This topic contains a solution. Click here to go to the answer

Author Question: Give an example of how the but for schedule might be used in a contractor's claim for added ... (Read 95 times)

pepyto

  • Hero Member
  • *****
  • Posts: 547
Give an example of how the but for schedule might be used in a contractor's claim for added compensation.
 
  What will be an ideal response?

Question 2

In the Blackhawk case, what role did construction schedules play in deciding the merits of the delay claim? Describe briefly how the schedules were prepared.
 
  What will be an ideal response?



Related Topics

Need homework help now?

Ask unlimited questions for free

Ask a Question
Marked as best answer by a Subject Expert

phuda

  • Sr. Member
  • ****
  • Posts: 348
Answer to Question 1

It must first be recognized that the but for schedule is a more compelling tool
if the contractor maintained an updated schedule throughout the construction period. It is
all the more compelling if the updated schedule bears a close resemblance to the
originally developed schedule, at least up to the event or occurrence that compromised
the schedule. The but for schedule is a good way to show how the schedule would
probably have been followed had it not be for a particular event or occurrence. Support
the owner suspends work for some reason, pushing the construction effort into the rainy
season. The but for schedule would essentially consist of the updated schedule with the
deletion of the owner's suspension of the work. In addition to the suspension period, the
schedule would show the added construction time (reduced productivity) that was
required as a result of performing work during the rainy season.

Answer to Question 2

As planned and as built CPM schedules were prepared after the project was
constructed. These were after-the-fact schedules developed by an independent -
consultant. Basing the information to be included in the schedule primarily on the
contractor's daily work logs, the consultant developed a schedule that was acceptable to
the Board of Contract Appeals. The Board acknowledged that the CPM schedule was
prepared well after events took place, but under close scrutiny of the Board, the schedule
was found to be acceptable. It is inferred, in this case, that the CPM schedule was critical
to the decision made by the Board.





 

Did you know?

In the United States, congenital cytomegalovirus causes one child to become disabled almost every hour. CMV is the leading preventable viral cause of development disability in newborns. These disabilities include hearing or vision loss, and cerebral palsy.

Did you know?

People about to have surgery must tell their health care providers about all supplements they take.

Did you know?

Complications of influenza include: bacterial pneumonia, ear and sinus infections, dehydration, and worsening of chronic conditions such as asthma, congestive heart failure, or diabetes.

Did you know?

Barbituric acid, the base material of barbiturates, was first synthesized in 1863 by Adolph von Bayer. His company later went on to synthesize aspirin for the first time, and Bayer aspirin is still a popular brand today.

Did you know?

Certain topical medications such as clotrimazole and betamethasone are not approved for use in children younger than 12 years of age. They must be used very cautiously, as directed by a doctor, to treat any child. Children have a much greater response to topical steroid medications.

For a complete list of videos, visit our video library